Posts Tagged construction industry
The 2016 budget statement was made on Monday 5 October 2015 by newly-appointed Minister of Finance & the Economy, Colm Imbert MP. Imbert is a professional engineer, so the fact that he lacked any formal certification in the financial field sparked much debate. The budget proposals have been made, so we are well past that point now.
These expenditure and revenue figures are from the Budget Statements, so no account has been taken of either actual outcomes or supplemental appropriations – this is the process used by the Government to obtain authorisation from the Parliament to exceed the approved spending limits in the national budget.
From: Afra Raymond <firstname.lastname@example.org>
Date: Thu, Sep 24, 2015 at 10:00 AM
Subject: Dismantling the Code of Silence
Noel Garcia served as General Manager of the Housing Development Corporation during the period in which critical decisions were made on the Las Alturas housing project. That project, in which two apartment buildings failed, is now the subject of a Commission of Enquiry. There have been several reports in the press (see below) that Mr Garcia was unwilling to testify to that Enquiry. We have been unable to locate any published responses from Mr Garcia to those reports.
Noel Garcia has now been appointed as Chairman of the UDECOTT Board. The JCC’s position is that the penalties for the failure or refusal to appear as a witness to a Commission of Enquiry must be increased sharply so as to discourage this deplorable behaviour. The present fine for non-attendance is only $2,000, which is why so many persons can show open disdain for a request to testify at a Commission of Enquiry.
The prospect of the Chairman of a State Enterprise declining to testify at a Commission of Enquiry is unacceptable and of course any continuing ambiguity can only feed suspicion.
The Las Alturas Enquiry resumes its evidence hearings on Monday 28th September 2015 and it would be a refreshing change from the ‘bad old days‘ if Mr Garcia, or his attorneys, were to promptly confirm his willingness to appear as a witness.
Noel Garcia responded via a media release, which was copied on social media on Sunday 27 September 2015 as follows:
Getting the Facts Right
I refer to a letter to the editor from Afra Raymond entitled “Dismantling the code of Silence” published in the September 27, 2015 edition of the Express Newspaper.
In his letter, Mr. Raymond, in reference to me and the Commission of Enquiry into the Las Alturas Project, speaks disparagingly of “the prospect of the Chairman of a State Enterprise declining to testify at a Commission of Enquiry”.
I wish to categorically state that I have never refused to give evidence before the Commission of Enquiry into the Las Alturas Project. Despite what Mr. Raymond claims to have read (and what he erroneously plainly believes), the Commission has never at any time contacted or subpoenaed me on the matter of the Las Alturas Project. This, although my postal address, email address and telephone number have remained unchanged for years.
For the record, I have never shirked my duty or my responsibility to give evidence before any court or any tribunal with respect to matters within my knowledge as a former employee of the HDC. I have previously given evidence in the High Court on behalf of the HDC and I have only recently filed an affidavit in support of the HDC’s position in another High Court matter. I am no stranger to and have given evidence repeatedly at Commissions of Enquiry including in the Piarco Airport Enquiry, the Landate Enquiry and the UFF Commission.
I wish to make my position abundantly clear that, were I to be subpoenaed or contacted to give evidence at the Commission of Enquiry into the Las Alturas Project, I would have absolutely no difficulty in assisting the Commission.
In his self-appointed role as guardian of the public conscience, Mr. Raymond ought to be more careful about permitting his officious zeal to lead him into making what can be considered to be defamatory imputations about others. Mr. Raymond’s self-confessed inability to locate any published responses from me to press reports he has read is no licence for him to do so.
This clarification was all we were seeking, so I responded later that night, on social media, as follows –
“…Noel Garcia’s post ‘Getting the Facts Right’ is very helpful, it is the first public response I have seen to the several articles earlier on this issue – I thank him for it…as I said elsewhere on FB yesterday, one of the Officials in the Las Alturas Enquiry told me that they had been ‘unable to locate’ Mr Garcia, to which I responded that as he was the new UDECOTT Chairman, it was now impossible to sustain that claim…”
For ease of reference – these are the previous press reports –
- Trinidad Guardian of 7th April 2015 – ‘Las Alturas Hearing resumes today‘
“…Singh also assured Ibrahim that efforts were being made to locate former executive chairman of the Urban Development Corporation of T&T Calder Hart, and former HDC general manager Noel Garcia, to have them appear before the Commission…” then “…Garcia is said to be living and working in Ghana. HDC’s attorney Vincent Nelson, QC, had previously indicated that Garcia had declined to provide a witness statement when asked, following which they lost contact with him. Seemingly dissatisfied with Mohammed’s answer that every effort was being made to have Hart present himself before the Commission, Ibrahim suggested that there were legal means which could be employed to compel him to appear.”Ibrahim has promised that accommodations would be made not to keep Hart unduly when he does appear, while there was also the recommendation that an offer be made to pay Garcia’s travel expenses back to T&T, in order for him to testify. Both Hart and Garcia have been deemed “important witnesses” in the enquiry. During the 13-day enquiry four witnesses have so far testified before the Commission…“
- Trinidad Express – 20th March 2015 – ‘HDC lawyers ‘lost all contact with Garcia’‘ –
“…Attorneys representing the Housing Development Corporation (HDC) have lost all contact with former HDC managing director Noel Garcia. This was revealed yesterday during the sitting of the commission of enquiry into the Las Alturas housing project at the Caribbean Court of Justice in Port of Spain.“Garcia, who was expected to be called as a witness in the enquiry, is said to be currently residing in Ghana.“Junior counsel for the commission Jagdeo Singh told the commission all attempts by HDC’s legal team to locate Garcia had been unsuccessful. “Every effort has been made thus far to locate Mr Garcia and at some point in time Mr Garcia was in communication with the legal team for the HDC, but he has since ceased all communication with them,” Singh said.“Nelson had said at a previous hearing that Garcia did not appear to be willing to testify in the proceedings.
“Chairman of the commission Mustapha Ibrahim noted Garcia’s participation in the enquiry was necessary, as he was a “very important witness”…“
- CTNT News – 5th March 2015 – ‘QC: Garcia’s presence crucial to Las Alturas Enquiry‘ –
“…The absence of former HDC Managing Director Noel Garcia at the Commission of Enquiry into the Las Alturas Housing Project was raised by the company’s Attorney on Day Four of the proceedings. Mr. Garcia is one of the key persons who would be best able to add the pieces to the already puzzling situation which led to the partial demolition of two towers at the million dollar housing complex due to shifting soil.”At Thursday’s session, the Attorney representing the Housing Development Corporation, Queen’s Counsel Vincent Nelson, mentioned that Mr. Garcia currently works and lives outside T&T.”The position there is that Mr. Noel Garcia, who is a pivotal person in the project at the time, is someone who really, although it is difficult because he is outside the jurisdiction for the Commission to summon him, he is an important and pivotal person in terms of what occurred at the time.”Mr. Nelson was then asked by the Commission Chairman Mustapha Ibrahim if any efforts were made to bring him back to T&T for the Enquiry, including offering to pay his airfare.
“No. We haven’t done so but obviously that is something that I could take instructions on. I am told we lost communication with him at the moment. So that is the position but we will make further efforts but in the meantime, the position is the Commission may consider whether to call the Board at the time and/or see when Mr. Garcia is available.’…” There is also a TV clip here.
- Newsday of 6th March 2015 – ‘Noel Garcia not willing to testify‘ –
“…NOEL Garcia, former managing director of the Housing Development Corporation (HDC), has indicated to lawyers for the HDC, that he is unwilling to testify at the Las Alturas Commission of Inquiry, attorney Vincent Nelson QC said yesterday…“
I have not seen any responses from Noel Garcia before his response on Sunday 27th September 2015.
This article is about the Las Alturas Enquiry into the collapse of two new Morvant apartment buildings erected by China Jiangsu International Corporation (CJIC) for the Housing Development Corporation (HDC). This Enquiry seems a politically-motivated one into a serious failure of professional practice which could have cost human lives. It is only in its opening stages, but it is already clear to me that this episode is one which contains serious lessons for our country in terms of the role of Enquiries; the role of the Chinese contractors; the culture of non-enforcement which we practice and of course, the impact of targets and political objectives on proper process. In the case of Las Alturas this is a large-scale multiple-housing project constructed on a former quarry-site on the Lady Young Road, just south of the lookout. Two apartment buildings which were completed in late 2010 were eventually declared uninhabitable due to severe cracking and the proposed demolition of those structures was announced at the end of May 2012. Each building comprised 24 three-bedroom/two-bathroom apartments, with the total cost of those buildings stated by HDC to be in the $29M range. The buildings were erected by CJIC on the design/build basis which usually places all responsibility for soil investigation, design and construction onto the contractor.
The role of Enquiries
The JCC offered to work with HDC in determining the causes of this serious failure and that offer was accepted, but our joint exercise did not last very long. The Commission of Enquiry was announced in September 2014 by the Prime Minister and despite the serious nature of the failure at this project, it seemed to suggest an attempt to discredit the Leader of the Opposition, Dr Keith Rowley, who was Minister of Housing between 2003-2007. I still feel that it was a poor choice of issue to investigate, given the burning questions at Invader’s Bay, the Beetham Water Recycling Project, UWI Debe and EFCL, to name just a few. The Terms of Reference of the Enquiry were published in the Gazette of 3 December 2014 and a five-month period was stipulated for its Report to be made to the President.The Enquiry, which is chaired by retired Justice of Appeal Mustapha Ibrahim, is to examine the causes of the structural failure of two blocks of apartments built in 2008-2010 for the HDC by CJIC. The other two Commissioners are eminent Structural Engineers, Dr. Myron Chin and Anthony Farrell. We have also seen reports of the contractor, CJIC, declining to appear at the Enquiry. I consider that refusal to be deplorable and a real sign that serious penalties need to be attached to that course of action. As it is, the fines for non-attendance are nominal, so people can refuse on a whim, since there are few prosecutions for that.
The role of the Chinese contractors
The really stunning revelation here is that the State was aware, since 2011, that these two buildings at Las Alturas had to be demolished. Despite this, CJIC was able, from early 2012 onwards, to compete for and secure the $500M+ contract for UWI’s Debe campus. The JCC protested at the poor process used in procuring that large-scale project. UWI Principal Professor Clement Sankat was advised that in view of the poor performance by CJIC in local State projects – including UTT Tamana, ETeck Wallerfield and various EFCL – no proper evaluation could proceed to recommend that further contracts be granted to that firm. Given that the normal pre-qualification process requires prospective bidders to identify claims, litigations or disputed matters, one can only wonder how CJIC was able to prevail in that project.
Culture of non-enforcement
One of the seldom-discussed findings of the Uff Enquiry was as to the lack of any culture of enforcement of contracts in the State construction sector, as set out in the sidebar. So, I was both thrilled and intrigued by the headline in this newspaper on Friday 6 March 2015 ‘HDC to sue Chinese contractor‘. The role and reputation of Chinese contractors in the local market have long been a bone of contention for the JCC. That statement was made in opening remarks by Vincent Nelson QC, who is the lead Counsel for HDC at this Enquiry –
“…The Housing Development Corporation (HDC) is moving to pursue legal action against China Jiangsu International Corporation (CJIC), the company contracted to construct the two towers at Las Alturas, Morvant, which subsequently had to be demolished because of structural damage resulting from land slippage. Attorney for the HDC, Vincent Nelson, was adamant about this as he delivered his opening statement at the Commission of Enquiry into the housing project yesterday at the Caribbean Court of Justice in Port of Spain…”
The culture of non-enforcement, considered with the chiefs at HDC (who transferred there after abruptly departing Caribbean Airlines), together with the special influence seemingly enjoyed by the Chinese contractors, all make me very sceptical as to whether a real and forceful lawsuit will ever emerge against CJIC.
The role of targets
Finally, one needs to consider the detrimental role of politically-motivated overambitious targets. The 2002 National Housing Policy set an unforgettable target of 100,000 new homes to be built in 10 years, which translates to an annual average of 10,000, which means a literally impossible 200 homes per week. Those are the facts behind the bizarre ‘numbers game’ which in turn likely had a decisive influence on the decision-makers at UDECOTT, HDC and of course the Housing Ministry. It would be useful, in this season of 100 houses a week and a billion dollars in land each year being promised, to reconsider the role of over-ambitious targets in distorting proper process. Curtis, the first sidebar is entitled
SIDEBAR: The Outline Timeline
This is only an outline, but it is instructive –
- December 2002 – UDECOTT acquires the Las Alturas site.
- 2003 – Initial layout prepared for a total of 120 apartments, which was revised later that year to 292 units given the Town & Country Planning Division’s advice on the allowable number of units.
- December 2003 – CJIC wins tender to design & build 297 apartments.
- November 2004 – Start on Site.
- 2005/2006 – Soil problems identified on part of the site.
- July 2005 – UDECOTT rejects project redesigns for lower units numbers of 142 and 167 apartments. Those redesigns were intended to avoid the unsuitable soils.
- July 2006 – the project is transferred from UDECOTT to HDC.
- 2008-2010 – Blocks H & I are built onto the areas reported to be unsuitable.
- 2011 – Blocks H & I are recommended to be demolished due to severe cracking.
We have also seen reports that both UDECOTT and the HDC were resistant to any reduction in unit numbers on the site.
SIDEBAR: Uff’s understanding
“Holding to account 29.21. …A recurrent feature of practice in the construction industry in Trinidad & Tobago is the extent to which rights and obligations prescribed by the Contract are or are not enforced. A simple example, discussed above, is the apparently mutual ignoring of contract provisions…”
At page 271 –
“…29.26. Underlying all the foregoing, however, is the question of enforcement of contractual rights and duties. What has been observed by the Commissioners is a culture of non-enforcement of rights, which appears to operate mutually, for example, by contractors not pressing for payment of outstanding sums while the employer does not enforce payment of liquidated damages. Whatever the explanation, the non-enforcement of contractual rights available to Government is a serious dereliction of duty on the part of those charged with protecting public funds. Equally, the non-pursuit of sums properly owed to commercial companies is a dereliction on the part of the directors of that company…”
The key point disclosed here is that contractual rights are seldom enforced in State contracts. A move to such a regular practice would require a major shift in our country’s governance culture.
This article is to engage the issues of falling national revenues due to price declines for fossil fuels, the ongoing commentary and the PM’s 8 January 2015 statement with its attendant criticisms. I am going to focus on the role of the real estate and construction sectors in this unfolding series of serious challenges.
This is the graph and table from my previous budget commentary ‘A Fistful of Dollars‘ to illustrate the trend in terms of how successive governments have attempted to balance revenues and expenditure.
The Public Procurement & Disposal of Public Property Bill was passed by the Senate on Tuesday 16 December 2014, completing its journey through the legislative process. That is an historic achievement for our country, so it is essential that we take our bearings and properly record the moment.
This important new law to control transactions in Public Money was the objective of a long-term, collective campaign by the Private Sector Civil Society group (PSCS) of which JCC was a member. The JCC met with the leaders of the Peoples Partnership in April 2010, with one of the key promises emerging from that meeting being that new Public Procurement laws would be passed within one year of an election victory. It has taken four and a half years for the government to achieve that.
This achievement was only possible because of our collective efforts. Ours was a diverse group which resolved to campaign together for this critical reform of our country’s laws to ensure effective control over transactions in Public Money. Read the rest of this entry »
The continued dispute over the Debe-Mon Desir Link of the Point Fortin Highway and the growing public debate over this issue require further attention to certain critical aspects.
The Armstrong Report was published in March 2013 after a process agreed between parties to the dispute over this highway link. It is a significant achievement in the journey to a more considered and consultative approach to national development. Given the shifting grounds of the dispute and the nature of the various statements, it is necessary to clarify some of the key issues.
The three main issues to be clarified are –
The Armstrong Report
The State’s position in relation to The Armstrong Report is a critical element of the dispute, so it is important to detail how this has morphed, like so much else in this matter. The Ministry of Works & Infrastructure Press Statement of 3 December 2012 ‘welcomed the inputs…from the JCC, FITUN, T&T Transparency Institute and Working Women‘ and went on to note that ‘the discussions had been very fruitful‘. That statement settled a basic framework for a Review of the elements of the link which were in dispute, with the preliminary Report to be provided within 60 days ‘to NIDCO for its consideration and publication thereafter’. Some people have tried to restrict the meaning of NIDCO’s ‘consideration’ of The Armstrong Report to a merely editorial vetting which implied no commitment to any post-publication consideration. The only conceivable reason for a party to this kind of process to have the right to review the preliminary Report would be to address factual errors in a situation in which the completed Report is of some significance.
At the post-Cabinet Press Briefing on Thursday 14 February 2013, the then ‘line Minister’ for NIDCO, Emmanuel George, said that the Report gave the State the ‘green light’, thanked the members of the Highway Review Committee and was reported to have agreed to ‘…as far as possible, accommodate their suggestions and recommendations…‘.
The only reasonable meaning to put to the State’s actions and agreements at the time was that there was a commitment to consider the recommendations of the Report. Of course we are now hearing from officials that there was no commitment to adopt or consider any of the recommendations in The Armstrong Report.
As a reality check, just ask yourself what would have been the position if The Armstrong Report had fully vindicated the State’s actions.
The Highway Contract
The high cost of halting construction is the main argument being used by the State to criticise The Armstrong Report and in its litigation with the Highway Re-Route Movement (HRM). On 25 February 2013, NIDCO wrote to JCC with its comments on the preliminary Report and the first page of that letter noted its concern that no consideration had been given to the fact that a $5.2Billion construction contract was in existence for this project. (Comment #2 on p. 30) That complaint is fundamentally misplaced, to say the least, since technical and scientific reviews do not normally take financial or commercial elements into account as material considerations.
At the level of general principles, two examples can clarify the position. In the widely-used two-envelope tendering situations, the tenderers submit separate technical and financial proposals, which are examined independently, with points awarded for each. The eventual selection is made after considering both those scores.
The most recent Commission of Enquiry was announced by the Prime Minister on 18 September 2014 into the HDC apartment blocks which had to be demolished in 2012 at Las Alturas in Morvant. (pp. 68-70) When HDC recognised that the stability of these newly-constructed hillside apartment blocks was in jeopardy, they obtained technical advice from professional engineers. It is doubtful whether those reports considered the financial and commercial fact that the building had already been erected or the losses that would accrue if they were to be demolished. Very doubtful. Indeed, one would rightly be suspicious of technical advice which was coloured by commercial considerations.
SIDEBAR: NIDCO’s reply to JCC
The JCC wrote to NIDCO on 10 October 2014 to request a detailed statement as to how the ten recommendations of The Armstrong Report had been treated and we met with NIDCO’s team on 17 October to discuss that request. NIDCO agreed to provide the details to JCC by Friday 24 October, but that reply is still awaited at the time of this writing.
Now, to deal directly with NIDCO’s criticism of The Armstrong Report, we need to note two facts –
- Terms of Reference – If, despite the general principle, NIDCO had wished to have the construction contract for the highway considered alongside the other factors to be examined during the 60-day Review, it could have made that request. The fact is that NIDCO never made that request, so the construction contract was not included in the terms of engagement for this review exercise.
- The Highway Review – If, having not requested that the construction contract be included in the review, NIDCO subsequently wanted it considered, there was an option to submit it. NIDCO never submitted the contract to the JCC or the Highway Review Committee.
Proceeding from the general principle to the particulars of this case, it is therefore clear why the Highway Review Committee did not consider the contract as part of the review process.
Note also that NIDCO has not submitted the contract to the Court during this extended litigation with the HRM.
Submitting the contract to either the Highway Review Committee or the Court would have exposed the underlying financial and commercial arrangements, as well as the repeated claims of adverse cost implications, to critical scrutiny.
Lastly, there is now a series of new statements emerging from the HRM and its supporters which did not form part of the original concerns of that group. The most striking of these is that the highway contract was not tendered. That allegation can be found in the HRM’s International Media Release of 24th September 2014 on their Facebook page and on the AVAAZ campaign webpage, as well as in other media statements by various persons supporting the HRM. That assertion is most alarming for two reasons.
Firstly, that is an entirely false assertion since the highway contract was tendered in 2010. Consider this extract from the top of page 19 of The Armstrong Report –
…On May 07, 2010, the closing date for this procurement, three proposals were submitted by 1.00 p.m. (from the 29 Request for Proposals issued)
The three entities submitting tenders were, in alphabetical order:
- China Railway Construction Corporation Limited;
- Construtora OAS Ltda (OAS); and
- GLF Construction Corporation…
On May 13, 2010 The NIDCO Evaluation Committee submitted its Final Report and recommended OAS as the Preferred Respondent, and so informed OAS by letter dated May 25, 2010…”
Secondly, those baseless assertions by the HRM show a lack of familiarity with the contents of The Armstrong Report. The HRM has relied heavily upon The Armstrong Report in its recent campaigning, so one can only wonder at the implications of these repeated claims.
Given the public positions taken by the protagonists, it seems unlikely that mediation can be a real option.
The Armstrong Report is a serious advance in terms of our nation’s development, being to my knowledge the first Civil Society review of a State-sponsored project in the Caribbean region. That Report would not have existed without Dr. Wayne Kublalsingh’s sacrifice, but the full benefits of the Report can only be realised by a proper and open consideration of its recommendations. Only then can we gain from the increased public attention to the complex issues of national development and really start to learn the lessons.
National development is a real and inescapable challenge which will continue to evolve, whoever is in government. That challenge can only be properly addressed by a fact-based approach adopted by all parties.
After a flurry of attempted explanations from the Minister of Planning & Sustainable Development, Dr. Bhoe Tewarie, as to the real meaning of the High Court’s 14 July ruling on the Invader’s Bay matter, the State has now appealed that ruling and applied for expedited hearing of the matter while having the judgment stayed.
What that means is that the State is asking the Court to agree an extension of the Stay of Execution until the appeal is decided, so that the requested information could be withheld while the case is being heard. Presumably, the State has asked for a speedy hearing so as to avoid any impression of them encouraging needless delay in this matter of high public concern.
This article will focus on the three critical findings in the judgment. I will be examining Dr. Tewarie’s statement to Parliament on Friday 18 July, alongside the facts and the actual High Court ruling.
Legal Professional Privilege
The very first point to be made in relation to this is that the reason given by the State for refusing the JCC’s request for this information was not originally ‘legal professional privilege’.
That reason for refusal was only advanced after the litigation started, literally arising out of the very briefcase of the State’s attorney, on his feet before Justice Seepersad on 4 December 2012.
We contested the State’s late introduction of these new reasons for refusal, but the Court ruled at para 37 –
- The Court…is of the view that the Defendant is entitled to rely upon additional reasons with respect to the refusal to disclose the said information…
The question of whether the legal opinions are privileged was ruled-upon by Justice Seepersad –
- It cannot be disputed that the said information requested, is information that would ordinarily attract legal professional privilege…
So that issue is not in dispute, in the Court’s mind at least. I continue to hold the view that it is highly-questionable to easily accept this notion of client confidentiality, given that the State ought to be acting on our common behalf.
In fact, no evidence was tendered nor was any real case made by the State as to the difficulties which would result from publishing the requested information. None. It is only now, with a ruling in the JCC’s favour, that we are getting these positions being advanced.
For the record, the JCC’s original request under the Freedom of Information Act (FoIA) was for the legal advices and the letters of instruction.
Consider this, from Dr. Tewarie’s opening statement –
The very first point that I wish to make with regard to the high court ruling is that there is no issue of disclosure here. There is no issue of failing to disclose or of wanting to withhold disclosures. The Government is not seeking to prevent disclosure of any matter nor is the Government fearful of making any disclosure of fact.
The only issue we are contesting is whether the advice of an Attorney to his/her client, which is generally regarded as privileged information, is subject to the jurisdiction of the Freedom of Information Act or whether, since it is a privileged exchange of information between Attorney and Client, it is exempt from the Act…”
If that is truly the case, with the State’s only concern being the possible adverse impact of releasing the legal advices, the question has to be – ‘Why not publish the letters of instruction now?’
Waiver of Privilege
A significant aspect of the case was as to the impact of Dr. Tewarie’s statement to the Senate on 28 February 2012, in reply to a question by then Independent Senator Dr. James Armstrong – see pg 716 of Hansard –
The answer to (c); the publication of the request for proposals was not the subject of nor required to be in conformity with the Central Tenders Board Act. Advice to this effect was received from the Legal Unit of the Ministry of Planning and the Economy, and subsequently from the Ministry of the Attorney General…
The point being advanced by the JCC was that a statement like that one, which purports to publicly disclose the very essence of the advice, has the effect of extinguishing the State’s right to suppress the document as being exempted.
The Court ruled clearly on this –
- The gist and nature of the legal advice was in fact revealed when the Minister’s response was made and this amounted to conduct that is inconsistent with the stance that the said legal advice is exempt from being disclosed under the Act by virtue of section 29(1)…
So, the High Court found that Dr. Tewarie’s statement to the Senate neutralized the State’s ‘legal professional privilege’. That is an important aspect of this ruling, given the frequency with which legal opinions and names are brandished by our leaders, always when convenient, of course.
The Public Interest Test
This ruling is significant in that Justice Seepersad weighed the existing ‘legal professional privilege’ – making a clear ruling on that at para 41 – against the ‘Public Interest Test’ set out in S.35 of the FoIA.
At one point it was widely reported that Dr. Tewarie was insisting that the ruling had nothing to do with transparency, but was only on the narrow issue of legal professional privilege.
The substance of Justice Seepersad’s ruling was at paras 85 & 86 –
- The nature of the project in this case and the process adopted by the Defendant to pursue the Request for Proposals process without regard to the provisions of the Central Tenders Board act, requires disclosure of all the relevant information that was considered before the said decision was taken and the refusal to provide the requested information can create a perception that there may have been misfeasance in the process and any such perception can result in the loss of public confidence. Every effort therefore ought to be made to avoid such a circumstance and if there is a valid and legally sound rationale for the adoption of the Request for Proposals process, then it must be in the public interest to disclose it and the rationale behind the process adopted ought not to be cloaked by a veil of secrecy.
- The public interest in having access to the requested information therefore is far more substantial than the Defendant’s interest in attempting to maintain any perceived confidentiality in relation to the said information…”
The real point here is that Justice Seepersad has carried out the Public Interest Test, as mandated at S.35 of the FoIA and ignored by the State in this matter, to find that the ‘legal professional privilege’ is subordinate to the Public Interest in this case, given all the evidence submitted to the Court.
The entire process possesses all the ingredients for corruption, I maintain that view.
Dr. Tewarie has repeatedly claimed that the process was transparent because he disclosed the assessment rules for the Invader’s Bay development at the T&T Contractors’ Association Dinner on Saturday 5 November 2011. That assertion is perfectly tautological, in that it is entirely true that the rules were revealed for the first time on that occasion, but it does not explain anything of substance. The decisive fact is that the closing-date for the Invader’s Bay RFP process was 4 October 2011, a full month before the rules were disclosed. That fact alone renders the entire process voidable and illegal.
What is more, we have to consider the widely-advertised public consultations on the redevelopment of King’s Wharf in San Fernando; the South-Western Peninsula development; the issue of ‘City-status’ for Chaguanas; Constitutional Reform and of course, the latest one, the Civil Society Board. The glaring question has to be – ‘When is the State hosting the first in its series of Public Consultations on the Invader’s Bay development?’
Finally, will this development process continue, while the legal arguments continue?